No. 98-1230
In the Supreme Court of the United States
OCTOBER TERM, 1998
HARDWICK BROTHERS COMPANY II, PETITIONER
v.
UNITED STATES OF AMERICA
ON PETITION FOR WRIT OF CERTIORARI
TO THE UNITED STATES COURT OF APPEALS
FOR THE FEDERAL CIRCUIT
BRIEF FOR THE UNITED STATES IN OPPOSITION
SETH P. WAXMAN
Solicitor General
Counsel of Record
DAVID W. OGDEN
Acting Assistant Attorney General
DAVID M. COHEN
JOHN C. HOYLE
BRIAN S. SMITH
Attorneys
Department of Justice
Washington, D.C. 20530-0001
(202) 514-2217
QUESTIONS PRESENTED
1. Whether the courts below erred in rejecting petitioner's claim of breach
of an implied warranty of the drawings and specifications on its construction
contract.
2. Whether the court of appeals erred in not ruling in petitioner's favor
on its claim of frustration and hindrance of performance of its construction
contract.
In the Supreme Court of the United States
OCTOBER TERM, 1998
No. 98-1230
HARDWICK BROTHERS COMPANY II, PETITIONER
v.
UNITED STATES OF AMERICA
ON PETITION FOR WRIT OF CERTIORARI
TO THE UNITED STATES COURT OF APPEALS
FOR THE FEDERAL CIRCUIT
BRIEF FOR THE UNITED STATES IN OPPOSITION
OPINIONS BELOW
The opinion of the court of appeals (Pet. App. 1a-12a) is unreported. The
opinion and order of the Court of Federal Claims (Pet. App. 13a-177a) is
reported at 36 Fed. Cl. 347.
JURISDICTION
The judgment of the court of appeals was entered on August 24, 1998. A petition
for rehearing was denied on November 2, 1998 (Pet. App. 178a-179a). The
petition for a writ of certiorari was filed on February 1, 1999 (a Monday).
The jurisdiction of this Court is invoked under 28 U.S.C. 1254(1).
STATEMENT
1. On May 27, 1977, the United States Army Corps of Engineers (Corps) awarded
petitioner a fixed-price contract for the construction of a flood control
levee project near the Missouri River. Pet. App. 3a. During contract performance,
petitioner suffered a series of delays and inefficiencies that were generally
attributable to wet soil conditions found at the job site. Ibid.1 On November
12, 1980, the Corps accepted the contract work as substantially complete.
Ibid.
2. In April 1986, petitioner submitted to the contracting officer certified
claims under the Contract Disputes Act of 1978, 41 U.S.C. 601 et seq., seeking
additional payments of $1.9 million, later amending the claims to request
$3,736,096. Pet. App. 3a. Petitioner's claims alleged that it was entitled
to additional payment on several bases, including purported differing site
conditions, defective specifications, incorrect contract interpretations,
and spoliation of evidence. After the contracting officer denied petitioner's
claims, petitioner filed a complaint in the United States Claims Court (now
the United States Court of Federal Claims) in December, 1988. Ibid. An eight-week
trial took place in 1990. On July 31, 1996, after a period in which the
case was dismissed for jurisdictional reasons and then reinstated after
appeal, the trial court issued a 70 page opinion denying all but a small
portion of petitioner's claims. Id. at 13a-177a; see also id. at 3a-4a.
The trial court awarded petitioner damages in the amount of $28,145 on March
26, 1997. Id. at 5a.
3. Petitioner appealed, alleging multiple errors in the trial court's decision.
The court of appeals affirmed on August 24, 1998. Pet. App. 1a-12a. The
court summarized the case as involving a "government contractor of
proven reliability and competence [who] lost upward of $3 million on a $3
million contract to build a levee system," and concluded that "because
the risk of extra costs from wet conditions at the construction site was
allocated to the contractor by the contract itself, there is no basis at
law to provide the relief the contractor seeks." Id. at 1a. The court
also noted that "[i]t is well-settled law that a contractor who fails
to perform an adequate site investigation bears the risk of any condition
that it could have discovered if the investigation had been reasonable."
Id. at 6a.
a. In holdings not challenged in this Court, the court of appeals rejected
petitioner's contentions that the United States Court of Federal Claims
had imposed additional burdens on contractors preparing to bid on a contract
and misconstrued the "Damage to Work" clause in the contract.
Pet. App. 7a-8a, 10a-11a.
b. The court of appeals also rejected petitioner's argument that "the
Court of Federal Claims improperly failed to apply the doctrine of implied
warranty in view of [petitioner's] compliance with the specifications provided
by the Corps." Pet. App. 8a. The court acknowledged that under United
States v. Spearin, 248 U.S. 132 (1918), "if the contractor is bound
to build according to plans and specifications prepared by the owner, the
contractor will not be responsible for the consequences of defects in the
plans and specifications." Pet. App. 8a-9a (quoting Spearin, 248
U.S. at 136). The court further explained, however, that the Spearin doctrine
applies only to "design specifications," and not to "[p]erformance
specifications." Id. at 9a (quoting Stuyvesant Dredging Co. v. United
States, 834 F.2d 1576, 1582 (Fed. Cir. 1987)). In a line of post-Spearin
cases, the court of appeals had honed the distinction between design and
performance specifications, explaining that "[d]esign specifications
explicitly state how the contract is to be performed and permit no deviations.
Performance specifications, on the other hand, specify the results to be
obtained, and leave it to the contractor to determine how to achieve those
results." Ibid. (quoting Stuyvesant Dredging Co., 834 F.2d at 1582).
The court of appeals concluded here that "the Court of Federal Claims's
categorization of the[] specifications [at issue] as performance specifications
was [not] clearly erroneous, and therefore * * * the Spearin doctrine, as
a matter of law, does not apply." Id. at 10a.
c. Finally, the court of appeals noted that "[t]he remainder of the
issues raised by Hardwick on appeal are essentially challenges to the Court
of Federal Claims's fact-findings," Pet. App. 11a, and concluded that
those factual findings were not clearly erroneous. Id. at 11a-12a.2
ARGUMENT
The decision of the court of appeals is correct and does not conflict with
any decision of this Court or any other court of appeals.3 Further review
is not warranted.
1. Petitioner errs in arguing (Pet. 7-13) that the court of appeals failed
properly to apply the doctrine regarding the warranty of government specifications
first articulated in United States v. Spearin, 248 U.S. 132 (1918).
The warranty of government specifications, known as the "Spearin doctrine,"
provides that if the government furnishes specifications for the production
or construction of an end product and proper application of those specifications
does not result in a satisfactory end product, the contractor will be compensated
for its efforts to produce the end product, notwithstanding the unsatisfactory
results. Pet. App. 8a-9a; United States v. Spearin, supra; Hercules, Inc.
v. United States, 516 U.S. 417 (1996). The Spearin doctrine has been discussed
and clarified over the years, often with the words "design" and
"performance" specifications used to differentiate between contracts
to which the specifications warranty does and does not apply. Stuyvesant
Dredging Co. v. United States, 834 F.2d 1576, 1582 (Fed. Cir. 1987); J.D.
Hedin Constr. Co. v. United States, 347 F.2d 235, 241 (Cl. Ct. 1965); Utility
Contractors, Inc. v. United States, 8 Cl. Ct 42, 50 (1985), aff'd, 790 F.2d
90 (Fed. Cir.), cert. denied, 479 U.S. 827 (1986); J.L. Simmons Co. v. United
States, 188 Ct. Cl. 684 (1969); Monitor Plastics Company, ASBCA No. 14447,
72-2 B.C.A. ¶ 9626 (Aug. 3, 1972). "Design specifications explicitly
state how the contract is to be performed and permit no deviations. Performance
specifications, on the other hand, specify the results to be obtained, and
leave it to the contractor to determine how to achieve those results."
Stuyvesant Dredging Co., 834 F.2d at 1582. The warranty applies only to
"design specifications" because only by utilizing specifications
in that category does the government deny the contractor's discretion and
require that work be done in a certain way. When the government imposes
such a requirement and the contractor complies, the government is bound
to accept what its requirements produce.
Petitioner criticizes the use of the labels "design" specification
and "performance" specification, suggesting they create a false
dichotomy which restricts the "ancient doctrine of Spearin." Pet.
7; see Pet. 7-9. This claim is without merit. As noted above, the courts
have consistently interpreted Spearin as applying only to the class of cases
in which the government has set forth exactly how the contract is to be
performed. That some courts use the term "design" specification
to describe that class of cases, while others do not, does not change the
nature of the specifications to which the warranty applies. Indeed, the
labels "design" and "performance" describe but do not
drive the inquiry; the underlying question is one of discretion. Do the
specifications describe in detail the materials to be used and/or the manner
in which the work is to be employed, or do they allow discretion, for example,
by setting forth a particular standard to be achieved but not requiring
that certain materials or methods be used? Only if the specifications fall
into the former category, regardless of the label used, will there be an
implied warranty under Spearin.
Contrary to petitioner's assertions, distinguishing between these two categories
of specifications does not create a false dichotomy (Pet. 7). Indeed, this
Court recognized the class of specifications to which the warranty applies
in Hercules, Inc., 516 U.S. at 425 (emphasis added):
When the Government provides specifications directing how a contract is
to be performed, the Government warrants that the contractor will be able
to perform the contract satisfactorily if it follows the specifications.
Because the Court in Hercules did not use the terms "design" or
"performance" specification, petitioner cites the decision in
support of its position. But petitioner overlooks the fact that the Hercules
decision is consistent with the established jurisprudence of the lower courts
holding that the warranty applies only when the government "direct[s]
how a contract is to be performed." Ibid.
The courts below properly declined to apply the Spearin warranty in this
case. Because petitioner's contract did not direct petitioner how it was
to build the flood control levee,4 the court of appeals correctly recognized
that petitioner's contract did not fall into the class of cases to which
the warranty applies. Pet. App. 8a-10a.
Indeed, the essence of petitioner's claim has never been that the design
of the flood control levee that petitioner built was defective-i.e., that
the plans for construction of the levee did not produce a functioning flood
control levee. Pet. App. 151a-152a. Instead, petitioner's primary complaint
is that the information depicted in the contract package relating to field
elevations, soil conditions, and job site wetness was inaccurate, that it
relied upon the inaccurate information when formulating its bid, and that
the inaccuracies caused it to incur increased costs during performance of
the contract. Ibid. Petitioner's claim is really a differing site conditions
claim, to which the Spearin doctrine has no applicability.
Petitioner, however, confuses the Spearin warranty with the government's
responsibilities regarding differing site conditions on federal construction
contracts. Petitioner contends that the court of appeals' rejection of its
Spearin arguments is "especially insidious" (Pet. 10) because
it eliminates the kind of "protect[ion]" (Pet. 12) provided to
contractors by the differing site condition provisions in government construction
contracts. Pet. 10-13. That allegation is without merit.
Under virtually every government construction contract, including petitioner's,
the contractor is protected by a contract clause that provides that material
differences between the subsurface physical features indicated in the contract
documents and the features actually encountered by the contractor will be
the basis for an equitable adjustment to the contract, to the extent that
the differing site conditions cause increased costs to the contractor. Pet.
App. 138a-149a; P.J. Maffei Bldg. Wrecking Corp. v. United States, 732 F.2d
913, 916 (Fed. Cir. 1984); A.S. McGaughan Co. v. United States, 24 Cl. Ct.
659, 664-665 (1991), aff'd, 980 F.2d 744 (Fed. Cir. 1992) (Table); John
Massman Contracting Co. v. United States, 23 Cl. Ct. 24, 30-31 (1991); Weeks
Dredging & Contracting, Inc. v. United States, 13 Cl. Ct 193, 218 (1987),
aff'd, 861 F.2d 728 (Fed. Cir. 1988) (Table); Pacific Alaska Contractors,
Inc. v. United States, 436 F.2d 461, 469 (Ct. Cl. 1971). This is the mechanism
by which government construction contractors are protected in the event
that information concerning physical features of the site, which is relied
upon by the contractor in bidding for the contract, proves to be materially
inaccurate.
The court of appeals' rejection of petitioner's Spearin argument does not
affect, in any way, the analysis of the government's responsibilities when
site condition information is materially inaccurate. In this case, the trial
court found that the site condition information provided to petitioner was
not inaccurate because it "gave sufficient notice to reasonably prudent
bidders" (Pet. App. 7a) of the conditions at the site. The court of
appeals upheld that finding as not clearly erroneous. Ibid. Therefore the
issue that remained before the court of appeals was simply whether the government's
warranty of design specifications applied to petitioner's claims. As explained
above, the court of appeals properly held that it did not.
Contrary to petitioner's contentions, the court of appeals' decision does
not affect the viability and applicability of the design warranty. Contractors
who expend futile efforts attempting to produce a product that will not
work because of a defective design have always been and will continue to
be compensated for their efforts. In contrast, contractors who construct
"performance specification" contracts will not be guaranteed that
their chosen methods of performance will be effective or produce a profit-but
that has never been so, before or after Spearin. Finally, contractors, whether
performing design or performance contracts, will still, as always, be compensated
for legitimate differing site conditions. The decision of the court of appeals
in this case is not contrary to precedent, prudence or "social policy."
2. Petitioner's argument (Pet. 14) that "the trial court erred in employing
a 'bad faith' standard under the theory of hindrance/frustration of performance"
is without merit. Petitioner never advanced to the trial court a claim that
the Corps frustrated the performance of its contract. In any event, the
trial court rejected petitioner's claims without relying on petitioner's
failure to establish bad faith.
The portion of the trial court's opinion set forth by petitioner as demonstrating
the trial court's error (Pet. 4-5; Pet. App. 91a), relates to petitioner's
claim of contour error. Although the trial court noted that there was no
bad faith in the Corps' investigation of alleged contour errors during construction
(ibid.), the trial court's rejection of petitioner's contour error claim
rested on a factual finding, not petitioner's failure to show bad faith:
The evidence is convincing that [petitioner]'s bid was not premised upon
the contours on the Plans. Since [petitioner] did not rely upon the contours,
any contours errors are immaterial. * * * The court also finds that [petitioner]
suffered no harm as a result of any alleged contour errors and that [petitioner]'s
related claims are all without merit under any theory of liability.
Pet. App. 91a-92a. Because the trial court did not rely on a bad faith analysis,
any claim of error based on application of that standard is without merit.
CONCLUSION
The petition for a writ of certiorari should be denied.
Respectfully submitted.
SETH P. WAXMAN
Solicitor General
DAVID W. OGDEN
Acting Assistant Attorney General
DAVID M. COHEN
JOHN C. HOYLE
BRIAN S. SMITH
Attorneys
APRIL 1999
1 The chronology of events during performance is set forth in detail in
the trial court's opinion. Pet. App. 13a-74a.
2 Petitioner does not contend in its petition that any of these factual
findings were clearly erroneous.
3 In its questions presented, petitioner claims that the court of appeals'
decision is "contrary to [those of] seven other circuits" (Pet.
i), but it does not identify the purportedly conflicting cases or otherwise
discuss any conflict with other circuits in the text of the petition.
4 The trial court described in detail many aspects of the contract concerning
which petitioner was given discretion over how to perform its work. Pet.
App. 152a-157a.